Change Order Form Create Change Order Form

Change Order Form

Updated Mar 16, 2026 5 (1) 3 Downloads

A Change Order Form documents modifications to a contract, detailing changes in scope, costs, or timelines, ensuring clarity between parties.

Create Change Order Form

Change Type

Select the main category that best describes the change being requested.

Provide details if 'Other' was selected.

Change Order Form Preview
View Document
Create
Download PDF

Table of Contents

What Is a Change Order Form?

A Change Order Form is a standardized document used to formally propose, document, and approve modifications to an existing project agreement or contract. It serves as a critical tool for project managers, contractors, and clients to ensure that any deviation from the original scope, cost, or timeline is clearly communicated, understood, and agreed upon by all involved parties. By providing a structured framework, this template helps prevent misunderstandings, disputes, and scope creep, maintaining project integrity and accountability throughout its lifecycle.

What Is Included

A well-structured Change Order Form template ensures all essential details of a proposed change are captured, facilitating clear communication and formal approval. The depth and number of sections can vary between a lightweight form for minor adjustments and a comprehensive form for significant project overhauls, but the core elements remain consistent.

  • Project Information - This section is crucial for identifying the specific project the change order pertains to, including the project name, ID, and relevant dates. It ensures the change is linked to the correct contractual agreement.
  • Original Scope Summary - A brief overview of the project's initial scope, cost, and timeline provides context for the proposed change. This helps stakeholders quickly understand what is being altered from the baseline.
  • Proposed Change Details - This is the core of the document, describing the specific modification requested. It should clearly outline what needs to be changed, added, or removed from the original plan, often including technical specifications or revised deliverables.
  • Reason for Change - Explaining why the change is necessary or beneficial is vital for justification. This could include unforeseen circumstances, client requests, regulatory updates, or opportunities for improvement, providing transparency to all parties.
  • Impact Analysis - This section details the potential effects of the proposed change on the project. It typically covers the impact on the project's scope, budget, schedule, resources, and quality, ensuring stakeholders understand the full ramifications.
  • Cost Adjustment - Clearly outlines any financial implications, whether an increase or decrease in the project budget. This includes a breakdown of new costs, revised pricing, and payment terms, ensuring financial clarity.
  • Schedule Adjustment - Specifies how the change will affect the project timeline, including revised start and end dates for affected tasks or the overall project. This helps manage expectations regarding delivery dates.
  • Approval Signatures - This critical section includes designated spaces for all necessary parties (e.g., client, contractor, project manager) to sign and date, indicating their formal agreement and acceptance of the change order terms.
  • Revision History/Change Log - For projects with multiple change orders, a log of all approved changes provides an auditable trail. This helps track cumulative impacts and ensures all documentation is current.

Who Should Use This Template?

Understanding who benefits most from a structured Change Order Form template, and who might find it less suitable, helps in its effective deployment.

Best For

  • Construction Companies & Contractors - Essential for managing scope changes in building projects, preventing disputes over materials, labor, and timelines.
  • Software Development Teams (Waterfall/Hybrid) - Ideal for projects with defined phases where changes to initial requirements need formal documentation and approval.
  • Consulting Firms & Agencies - Useful when project scope evolves based on client feedback or new discoveries, ensuring services rendered align with revised agreements.
  • Manufacturing & Engineering Firms - Critical for documenting design modifications, material changes, or process adjustments that impact production schedules and costs.
  • Mid-to-Large Sized Organizations - Particularly those with formal project governance processes and a need for detailed audit trails and accountability across departments.
  • Projects with Fixed-Price Contracts - Provides a clear mechanism to adjust the contract value when scope changes occur, protecting both parties from unexpected costs.

Not Ideal For

  • Highly Agile Software Development Teams - Agile methodologies often embrace continuous change through backlog grooming and sprints, where formal change orders for every small iteration might introduce unnecessary overhead.
  • Very Small, Informal Projects - For internal, low-stakes projects with a very small team and flexible scope, a full Change Order Form might be overkill, with verbal agreements or simple email confirmations sufficing.
  • Exploratory R&D Initiatives - Projects focused on discovery and innovation, where the scope is inherently fluid and undefined, may find rigid change order processes restrictive.
  • Projects with Time & Materials Contracts (without caps) - While some documentation is always good, the nature of these contracts means costs and timelines are inherently more flexible, reducing the need for formal change orders for every minor adjustment.

Quick Start Guide

Implementing a Change Order Form template effectively requires a structured approach to ensure all project modifications are handled consistently and transparently.

  1. Identify the Need for Change - The first step is recognizing when a project deviation is significant enough to warrant a formal change order. This could be a client request, an unforeseen site condition, a regulatory update, or a new opportunity. Distinguish between minor adjustments that can be handled informally and those impacting scope, cost, or schedule.
  2. Document the Proposed Change Details - Clearly articulate what specifically needs to change. Use the 'Proposed Change Details' section to provide a precise description, including any new specifications, revised deliverables, or removed components. Be factual and objective, avoiding ambiguity to prevent future misinterpretations.
  3. Conduct a Comprehensive Impact Analysis - Before presenting the change, thoroughly assess its ripple effects across the project. Detail the impact on budget, timeline, resources, quality, and any other relevant project constraints. This analysis forms the basis for the 'Cost Adjustment' and 'Schedule Adjustment' sections and is crucial for informed decision-making.
  4. Draft the Change Order Form - Fill in all relevant sections of your Change Order Form template, including project information, original scope summary, the proposed change, its justification, and the detailed impact analysis. Ensure all financial and schedule adjustments are clearly calculated and presented.
  5. Present to Stakeholders for Review and Negotiation - Share the drafted Change Order Form with all affected parties, including the client, project sponsor, and relevant team leads. Be prepared to discuss the proposed changes, justify the impacts, and negotiate terms if necessary. Transparency during this stage is key to gaining buy-found and agreement.
  6. Obtain Formal Approvals and Signatures - Once all parties agree on the terms, ensure the form is signed and dated by every required signatory. This formalizes the agreement and makes the change official. Without these signatures, the change is not binding and should not proceed.
  7. Update Project Documentation and Plans - Immediately after approval, integrate the change order details into all relevant project documentation, including the project plan, schedule, budget, and scope statement. Communicate the approved changes to the entire project team to ensure everyone is working with the most current information.
  8. Archive the Approved Change Order - Store the signed Change Order Form in a secure, accessible location as part of the project's official records. This ensures an auditable trail for future reference, dispute resolution, or project closure activities.

Frequently Asked Questions

A Change Order Form is typically required whenever there is a deviation from the originally agreed-upon project scope, cost, or timeline. This ensures that all parties formally acknowledge and approve the modification before implementation.
A change request is an informal or formal proposal for a modification to a project, while a change order is the official, approved document that formalizes that change request. A change request becomes a change order once it has been reviewed, approved, and signed by all necessary stakeholders.
Anyone involved in the project, including the client, contractor, project manager, or even a team member, can initiate the need for a change order. However, the formal documentation and approval process typically involves the project manager or a designated contract administrator.
Yes, a Change Order Form can absolutely be rejected if the proposed changes are deemed unnecessary, too costly, or do not align with project objectives. Rejection often leads to further negotiation or the exploration of alternative solutions.
A Change Order Form directly impacts project timelines by formally adjusting task durations, adding new milestones, or shifting delivery dates. The 'Schedule Adjustment' section of the form explicitly details these modifications, ensuring all stakeholders are aware of the revised schedule.
While this content does not provide legal advice, a properly executed Change Order Form, signed by all parties to an original contract, typically becomes an amendment to that contract. This makes its terms and conditions enforceable as part of the overall agreement.
For urgent changes, a common practice is to implement a provisional approval, often via email or quick meeting minutes, followed by a formal Change Order Form as soon as possible. This ensures critical work isn't delayed while still maintaining proper documentation.
A project can have multiple Change Order Forms throughout its lifecycle, depending on its complexity and evolving needs. Each change order should be uniquely identified and tracked to maintain a clear record of all modifications to the original project plan.

Change Order Form Sample

0% Complete 0/0 Fields

CHANGE ORDER FORM

This Change Order ("Change Order") is entered into on , by and between:

I. PARTIES TO THE CHANGE ORDER

Owner/Client:
Name:
Address:
Phone:
Email:

Contractor/Subcontractor:
Name:
Address:
Phone:
Email:

(Hereinafter collectively referred to as the "Parties" and individually as a "Party").

II. RECITALS

WHEREAS, the Parties previously entered into a written agreement for the performance of certain work, identified as the "Original Contract," dated , concerning the project known as:

Project Name:
Project Number (if applicable):
Project Location:

WHEREAS, the Parties now desire to modify certain terms, scope, timeline, or cost of the Original Contract as set forth herein.

NOW, THEREFORE, in consideration of the mutual covenants and promises contained herein, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the Parties agree as follows:

III. CHANGE ORDER DETAILS

1. Change Order Number: This Change Order is designated as Change Order No. .

2. Description of Change: The Original Contract is hereby modified as follows. This change specifically impacts the following aspects of the project (e.g., scope of work, materials, specifications, methods, etc.):

3. Reason for Change: The reason(s) necessitating this Change Order are:

4. Impact on Contract Price:

a. Original Contract Price: $

b. Change in Contract Price (Increase/Decrease): $

c. New Contract Price (Original Contract Price +/- Change in Contract Price): $

5. Impact on Contract Time:

a. Original Contract Completion Date:

b. Change in Contract Time (Extension/Reduction in Days): days

c. New Contract Completion Date (Original Completion Date +/- Change in Time):

6. Other Impacts (if any):

IV. TERMS AND CONDITIONS

1. Incorporation: This Change Order shall be deemed an integral part of the Original Contract, and all terms and conditions of the Original Contract not expressly modified herein shall remain in full force and effect.

2. Governing Law: This Change Order shall be governed by and construed in accordance with the laws of the State of , without regard to its conflict of laws principles.

3. Entire Agreement: This Change Order, together with the Original Contract, constitutes the entire agreement between the Parties with respect to the subject matter hereof and supersedes all prior discussions, negotiations, and agreements, whether oral or written.

4. Severability: If any provision of this Change Order is held to be invalid, illegal, or unenforceable by a court of competent jurisdiction, such provision shall be severed from this Change Order, and the remaining provisions shall remain in full force and effect.

5. Waiver: No waiver of any provision of this Change Order shall be effective unless made in writing and signed by the Party against whom the waiver is sought to be enforced. The failure of either Party to enforce any provision of this Change Order shall not be construed as a waiver of such provision or of the right to enforce it at a later time.

6. Headings: The headings used in this Change Order are for convenience only and shall not affect the interpretation or construction of any provision hereof.

7. Counterparts: This Change Order may be executed in one or more counterparts, each of which shall be deemed an original, but all of which together shall constitute one and the same instrument.

8. Successors and Assigns: This Change Order shall be binding upon and inure to the benefit of the Parties hereto and their respective heirs, executors, administrators, successors, and permitted assigns.

9. Amendment: Any amendment or modification to this Change Order must be in writing and signed by both Parties.

10. Notices: All notices, requests, demands, and other communications required or permitted under this Change Order shall be in writing and shall be deemed to have been duly given when delivered personally, sent by certified or registered mail, return receipt requested, or by recognized overnight courier service, to the addresses set forth in Section I of this Change Order, or to such other address as a Party may designate by written notice to the other Party.

V. SIGNATURES

OWNER/CLIENT:
Signature: _________________________
Print Name: _______________
Date:
Address: _______________

CONTRACTOR/SUBCONTRACTOR:
Signature: _________________________
Print Name: _______________
Date:
Address: _______________

Not the form you're looking for?

Try our legal document generator to create a custom document

Ask about a Change Order Form

Disclaimer: The templates available on this website are provided for general informational purposes only and do not constitute legal advice. They are not intended to be, and should not be interpreted as, compliant with any specific legal, regulatory, or privacy requirements. These templates are not a replacement for professional legal guidance and should not be relied upon for any particular matter or circumstance. Users are strongly encouraged to seek advice from a qualified attorney licensed in their jurisdiction before using, modifying, or relying on any template.

All templates are provided on an "as is," "with all faults," and "as available" basis. The provider disclaims any and all warranties of any kind, whether express, implied, statutory, or otherwise, including without limitation warranties of merchantability, fitness for a particular purpose, title, or non-infringement.

LegalTemplates.com makes no guarantees or representations regarding the accuracy, completeness, expected outcomes, or reliability of the materials contained in these templates or any materials referenced or linked from them.

We Value Your Privacy

We use cookies to enhance your browsing experience, analyze site traffic, and personalize content. We do not sell your personal data. By clicking "Accept All," you consent to our use of cookies. For more information, please read our Privacy Policy.